Back to GetFilings.com



Table of Contents

FORM 10-Q

UNITED STATES SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

     x QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE
          SECURITIES EXCHANGE ACT OF 1934

For the Quarterly period ended September 30, 2004

OR

     o TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE
          SECURITIES EXCHANGE ACT OF 1934

For the transition period from ____ to ____

Commission File Number 1-12815

CHICAGO BRIDGE & IRON COMPANY N.V.

     
Incorporated in The Netherlands   IRS Identification Number: Not Applicable

Polarisavenue 31
2132 JH Hoofddorp
The Netherlands
31-23-5685660
(Address and telephone number of principal executive offices)

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.

YESx     NOo

Indicate by check mark whether the registrant is an accelerated filer (as defined in Rule 12b-2 of the exchange act).

YESx     NOo

The number of shares outstanding of a single class of common stock as of October 31, 2004 – 48,115,928

1


CHICAGO BRIDGE & IRON COMPANY N.V. AND SUBSIDIARIES
Table of Contents

                     
                Page
PART I.       FINANCIAL INFORMATION        
    Item 1   Consolidated Financial Statements        
          Statements of Income
Three and Nine Months Ended September 30, 2004 and 2003
   
3
 
          Balance Sheets
September 30, 2004 and December 31, 2003
    4  
          Statements of Cash Flows
Nine Months Ended September 30, 2004 and 2003
    5  
          Notes to Consolidated Financial Statements     6  
    Item 2   Management’s Discussion and Analysis of Financial Condition and Results of Operations     14  
    Item 3   Quantitative and Qualitative Disclosures About Market Risk     19  
    Item 4   Controls and Procedures     20  
PART II.       OTHER INFORMATION        
    Item 1   Legal Proceedings     20  
    Item 6   Exhibits and Reports on Form 8-K     22  
SIGNATURES             23  
 Certification pursuant to Section 302
 Certification pursuant to Section 302
 Certification pursuant to Section 906
 Certification pursuant to Section 906

2


Table of Contents

CHICAGO BRIDGE & IRON COMPANY N.V. AND SUBSIDIARIES
CONSOLIDATED STATEMENTS OF INCOME

(In thousands, except per share data)
(Unaudited)

                                 
    Three Months Ended   Nine Months Ended
    September 30,
  September 30,
    2004
  2003
  2004
  2003
Revenue
  $ 465,539     $ 429,123     $ 1,324,465     $ 1,140,741  
Cost of revenue
    405,869       377,610       1,188,467       1,000,212  
 
   
 
     
 
     
 
     
 
 
Gross profit
    59,670       51,513       135,998       140,529  
Selling and administrative expenses
    23,347       25,050       70,810       68,135  
Intangibles amortization (Note 3)
    404       650       1,429       1,937  
Other operating expense (income), net
    180       (2,249 )     60       (2,730 )
 
   
 
     
 
     
 
     
 
 
Income from operations
    35,739       28,062       63,699       73,187  
Interest expense
    (2,380 )     (1,648 )     (5,840 )     (4,893 )
Interest income
    717       85       1,166       1,061  
 
   
 
     
 
     
 
     
 
 
Income before taxes and minority interest
    34,076       26,499       59,025       69,355  
Income tax expense
    (11,494 )     (8,055 )     (19,478 )     (20,973 )
 
   
 
     
 
     
 
     
 
 
Income before minority interest
    22,582       18,444       39,547       48,382  
Minority interest in (income) loss
    (962 )     (416 )     1,621       (1,126 )
 
   
 
     
 
     
 
     
 
 
Net income
  $ 21,620     $ 18,028     $ 41,168     $ 47,256  
 
   
 
     
 
     
 
     
 
 
Net income per share (Note 1):
                               
Basic
  $ 0.45     $ 0.39     $ 0.87     $ 1.05  
Diluted
  $ 0.44     $ 0.37     $ 0.83     $ 1.00  
Weighted average shares outstanding:
                               
Basic
    47,879       45,986       47,490       45,001  
Diluted
    49,465       48,527       49,424       47,219  
Dividends on shares:
                               
Amount
  $ 1,919     $ 1,842     $ 5,712     $ 5,404  
Per share
  $ 0.04     $ 0.04     $ 0.12     $ 0.12  

The accompanying Notes to Consolidated Financial Statements are an integral part of these financial statements.

3


Table of Contents

CHICAGO BRIDGE & IRON COMPANY N.V. AND SUBSIDIARIES
CONSOLIDATED BALANCE SHEETS
(In thousands, except share data)

                 
    September 30,   December 31,
    2004
  2003
    (Unaudited)        
Assets
               
Cash and cash equivalents
  $ 143,259     $ 112,918  
Accounts receivable, net of allowance for doubtful accounts of $1,429 in
2004 and $1,178 in 2003
    230,600       200,521  
Contracts in progress with costs and estimated earnings exceeding related progress billings
    147,559       142,235  
Deferred income taxes
    24,663       23,509  
Other current assets
    26,787       33,244  
 
   
 
     
 
 
Total current assets
    572,868       512,427  
 
   
 
     
 
 
Property and equipment, net
    119,701       124,505  
Non-current contract retentions
    9,232       11,254  
Deferred income taxes
    5,135       2,876  
Goodwill
    232,364       219,033  
Other intangibles
    29,520       30,949  
Other non-current assets
    29,156       31,318  
 
   
 
     
 
 
Total assets
  $ 997,976     $ 932,362  
 
   
 
     
 
 
Liabilities
               
Notes payable
  $ 8,577     $ 1,901  
Current maturity of long-term debt
    25,000        
Accounts payable
    128,614       143,258  
Accrued liabilities
    86,929       95,237  
Contracts in progress with progress billings exceeding related costs and estimated earnings
    148,855       130,497  
Income taxes payable
    4,817       5,359  
 
   
 
     
 
 
Total current liabilities
    402,792       376,252  
 
   
 
     
 
 
Long-term debt
    50,000       75,000  
Other non-current liabilities
    100,266       85,038  
Minority interest in subsidiaries
    4,927       6,908  
 
   
 
     
 
 
Total liabilities
    557,985       543,198  
 
   
 
     
 
 
Shareholders’ Equity
               
Common stock, Euro .01 par value; shares authorized: 125,000,000 in 2004 and 80,000,000
in 2003;
               
shares issued: 48,012,530 in 2004 and 46,697,732 in 2003;
               
shares outstanding: 47,963,599 in 2004 and 46,694,415 in 2003
    491       475  
Additional paid-in capital
    302,822       283,625  
Retained earnings
    161,977       126,521  
Stock held in Trust
    (11,693 )     (11,719 )
Treasury stock, at cost; 48,931 in 2004 and 3,317 in 2003
    (1,495 )     (108 )
Accumulated other comprehensive loss
    (12,111 )     (9,630 )
 
   
 
     
 
 
Total shareholders’ equity
    439,991       389,164  
 
   
 
     
 
 
Total liabilities and shareholders’ equity
  $ 997,976     $ 932,362  
 
   
 
     
 
 

The accompanying Notes to Consolidated Financial Statements are an integral part of these financial statements.

4


Table of Contents

CHICAGO BRIDGE & IRON COMPANY N.V. AND SUBSIDIARIES
CONSOLIDATED STATEMENTS OF CASH FLOWS
(In thousands)
(Unaudited)

                 
    Nine Months Ended
    September 30,
    2004
  2003
Cash Flows from Operating Activities
               
Net income
  $ 41,168     $ 47,256  
Adjustments to reconcile net income to net cash provided by operating activities:
               
Payments related to exit costs
    (1,327 )     (1,511 )
Depreciation and amortization
    16,511       15,559  
Loss (Gain) on sale of property and equipment
    60       (2,730 )
Change in operating assets and liabilities (see below)
    (18,519 )     (8,936 )
 
   
 
     
 
 
Net cash provided by operating activities
    37,893       49,638  
 
   
 
     
 
 
Cash Flows from Investing Activities
               
Cost of business acquisitions, net of cash acquired
    (10,475 )     (54,448 )
Capital expenditures
    (11,977 )     (27,586 )
Proceeds from sale of property and equipment
    1,122       6,489  
 
   
 
     
 
 
Net cash used in investing activities
    (21,330 )     (75,545 )
 
   
 
     
 
 
Cash Flows from Financing Activities
               
Increase/(decrease) in notes payable
    8,576       (7 )
Purchase of treasury stock
    (1,386 )     (2,027 )
Issuance of treasury stock
          4,200  
Issuance of common stock
    12,300       21,990  
Dividends paid
    (5,712 )     (5,404 )
 
   
 
     
 
 
Net cash provided by financing activities
    13,778       18,752  
 
   
 
     
 
 
Increase/(decrease) in cash and cash equivalents
    30,341       (7,155 )
Cash and cash equivalents, beginning of the year
    112,918       102,536  
 
   
 
     
 
 
Cash and cash equivalents, end of the period
  $ 143,259     $ 95,381  
 
   
 
     
 
 
Change in Operating Assets and Liabilities
               
(Increase)/decrease in receivables, net
  $ (30,079 )   $ 1,004  
Decrease/(increase) in contracts in progress, net
    13,028       (47,906 )
Decrease/(increase) in non-current contract retentions
    2,022       (6,404 )
(Decrease)/increase in accounts payable
    (14,644 )     31,069  
 
   
 
     
 
 
Change in contract capital
    (29,673 )     (22,237 )
Decrease/(increase) in other current assets
    7,193       (2,763 )
Increase in income taxes payable and deferred income taxes
    7,014       11,073  
(Decrease)/increase in accrued and other non-current liabilities
    (662 )     10,118  
Increase in other
    (2,391 )     (5,127 )
 
   
 
     
 
 
Total
  $ (18,519 )   $ (8,936 )
 
   
 
     
 
 

The accompanying Notes to Consolidated Financial Statements are an integral part of these financial statements.

5


Table of Contents

CHICAGO BRIDGE & IRON COMPANY N.V. AND SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS
September 30, 2004
(in thousands, except per share data)
(Unaudited)

1. Significant Accounting Policies

Basis of PresentationThe accompanying unaudited consolidated financial statements for Chicago Bridge & Iron Company N.V. and Subsidiaries (“CB&I”) have been prepared pursuant to the rules and regulations of the U.S. Securities and Exchange Commission. In the opinion of management, our unaudited consolidated financial statements include all adjustments necessary for a fair presentation of our financial position as of September 30, 2004, our results of operations for each of the three-month and nine-month periods ended September 30, 2004 and 2003, and our cash flows for each of the nine-month periods ended September 30, 2004 and 2003. The consolidated balance sheet at December 31, 2003 is derived from the December 31, 2003 audited consolidated financial statements. Although management believes the disclosures in these financial statements are adequate to make the information presented not misleading, certain information and footnote disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America have been condensed or omitted pursuant to the rules and regulations of the Securities and Exchange Commission. The results of operations and cash flows for the interim periods are not necessarily indicative of the results to be expected for the full year. The accompanying unaudited interim consolidated financial statements should be read in conjunction with our consolidated financial statements and notes thereto included in our 2003 Annual Report on Form 10-K.

Reclassification of Prior Year Balances—Certain prior year balances have been reclassified to conform with the current year presentation.

Revenue Recognition—Revenue is recognized using the percentage-of-completion method. A significant portion of our work is performed on a fixed price or lump sum basis. The balance of our work is performed on variations of cost reimbursable and target price approaches. Contract revenue is accrued based on the percentage that actual costs-to-date bear to total estimated costs. We utilize this cost-to-cost approach as we believe this method is less subjective than relying on assessments of physical progress. We follow the guidance of the Statement of Position 81-1, “Accounting for Performance of Construction-Type and Certain Production-Type Contracts,” for accounting policy relating to our use of the percentage-of-completion method, estimating costs, revenue recognition and claim recognition. The use of estimated cost to complete each contract, while the most widely recognized method used for percentage-of-completion accounting, is a significant variable in the process of determining income earned and is a significant factor in the accounting for contracts. The cumulative impact of revisions in total cost estimates during the progress of work is reflected in the period in which these changes become known. Due to the various estimates inherent in our contract accounting, actual results could differ from those estimates.

Contract revenue reflects the original contract price adjusted for approved change orders and estimated minimum recoveries of unapproved change orders and claims. We recognize unapproved change orders and claims to the extent that related costs have been incurred when it is probable that they will result in additional contract revenue and their value can be reliably estimated. At September 30, 2004 and December 31, 2003, we had net outstanding unapproved change orders/claims recognized of $23,404 and $6,970, respectively. Losses expected to be incurred on contracts in progress are charged to income in the period such losses are known. Provisions for additional costs associated with contracts projected to be in a significant loss position at September 30, 2004 resulted in a $2,103 and $48,403 charge to income in the three and nine month periods ended September 30, 2004, respectively.

Cost and estimated earnings to date in excess of progress billings on contracts in process represent the cumulative revenue recognized less the cumulative billings to the customer. Any billed revenue that has not been collected is reported as accounts receivable. Unbilled revenue is reported as contracts in progress with costs and estimated earnings exceeding related progress billings on the consolidated balance sheet. The timing of when we bill our

6


Table of Contents

customers is generally contingent on completion of certain phases of the work as stipulated in the contract. Progress billings in accounts receivable at September 30, 2004 and December 31, 2003 were currently due and included retentions totaling $30,635 and $32,533, respectively, to be collected within one year. Contract retentions collectible beyond one year are included in non-current contract retentions on our consolidated balance sheets. Cost of revenue includes direct contract costs such as material and construction labor, and indirect costs which are attributable to contract activity.

New Accounting Standards—In December 2003, the Financial Accounting Standards Board (“FASB”) issued Statement of Financial Accounting Standards (“SFAS”) No. 132 (revised 2003), “Employers’ Disclosures about Pensions and Other Postretirement Benefits.” The revised standard requires annual and interim disclosures in addition to those in the original standard concerning the assets, obligations, cash flows, and net periodic benefit cost of defined benefit pension plans and other defined benefit postretirement plans. This statement is effective for fiscal years ending after December 15, 2003. See Note 5 for the interim disclosure requirements of SFAS No. 132 (revised 2003).

In May 2004, the FASB issued FASB Staff Position (“FSP”) No. 106-2 (“FSP 106-2”), “Accounting and Disclosure Requirements Related to the Medicare Prescription Drug, Improvement and Modernization Act of 2003,” which supersedes FSP 106-1. FSP 106-2 provides guidance on the accounting for the effects of the Medicare Prescription Drug, Improvement and Modernization Act of 2003 (the “Act”) for employers that sponsor postretirement health care plans that provide prescription drug benefits. FSP 106-2 also requires certain disclosures regarding the effect of the federal subsidy provided by the Act. FSP 106-2 is effective for the first interim and annual period beginning after June 15, 2004. Although we are currently evaluating our qualification status for any Medicare Prescription Drug subsidies, the effect of our adoption of FSP 106-2 is not anticipated to have a significant impact on our financial condition or results of operations.

Earnings Per Share Computations—Basic earnings per share (“EPS”) is calculated by dividing our net income by the weighted average number of common shares outstanding for the period, which includes stock held in trust. Diluted EPS reflects the assumed conversion of all dilutive securities, consisting of employee stock options/restricted shares/performance shares and directors deferred fee shares.

The following schedule reconciles the income and shares utilized in the basic and diluted EPS computations:

                                      
    Three Months Ended   Nine Months Ended
    September 30,
  September 30,
    2004
  2003
  2004
  2003
Net income
  $ 21,620     $ 18,028     $ 41,168     $ 47,256  
 
   
 
     
 
     
 
     
 
 
Weighted average shares outstanding — basic
    47,879       45,986       47,490       45,001  
Effect of stock options/restricted shares/performance shares
    1,533       2,491       1,881       2,169  
Effect of directors deferred fee shares
    53       50       53       49  
 
   
 
     
 
     
 
     
 
 
Weighted average shares outstanding — diluted
    49,465       48,527       49,424       47,219  
 
   
 
     
 
     
 
     
 
 
Net income per share
                               
Basic
  $ 0.45     $ 0.39     $ 0.87     $ 1.05  
Diluted
  $ 0.44     $ 0.37     $ 0.83     $ 1.00  

Stock Plans—We account for stock-based compensation using the intrinsic value method prescribed by Accounting Principles Board Opinion No. 25, “Accounting for Stock Issued to Employees,” and related Interpretations. Accordingly, compensation cost for stock options is measured as the excess, if any, of the quoted market price of our stock at the date of the grant over the amount an employee must pay to acquire the stock, subject to any vesting

7


Table of Contents

provisions. Reported net income does not include any compensation expense associated with stock options, but does include compensation expense associated with restricted stock and performance share awards.

Had compensation expense for the Employee Stock Purchase Plan and Long-Term Incentive Plans been determined consistent with the fair value method of SFAS No. 123, “Accounting for Stock-Based Compensation” (using the Black-Scholes pricing model for stock options), our net income and net income per common share would have reflected the following pro forma amounts:

                                 
    Three Months Ended   Nine Months Ended
    September 30,
  September 30,
    2004
  2003
  2004
  2003
Net Income, as reported
  $ 21,620     $ 18,028     $ 41,168     $ 47,256  
 
   
 
     
 
     
 
     
 
 
Add: Stock-based compensation for restricted stock and performance share awards included in reported net income, net of tax
    (87 )     933       520       1,704  
Deduct: Stock-based compensation determined
under the fair value method, net of tax
    (651 )     (1,890 )     (2,005 )     (4,514 )
 
   
 
     
 
     
 
     
 
 
Pro forma net income
  $ 20,882     $ 17,071     $ 39,683     $ 44,446  
 
   
 
     
 
     
 
     
 
 
Basic EPS
                               
As reported
  $ 0.45     $ 0.39     $ 0.87     $ 1.05  
Pro forma
  $ 0.44     $ 0.37     $ 0.84     $ 0.99  
 
   
 
     
 
     
 
     
 
 
Diluted EPS
                               
As reported
  $ 0.44     $ 0.37     $ 0.83     $ 1.00  
Pro forma
  $ 0.42     $ 0.35     $ 0.80     $ 0.94  

Using the Black-Scholes option-pricing model, the fair value of each option grant is estimated on the date of grant based on the following weighted-average assumptions:

                                 
    Three Months Ended   Nine Months Ended
    September 30,
  September 30,
    2004
  2003
  2004
  2003
Risk-free interest rate
    4.18 %     3.06 %     3.81 %     3.28 %
Expected dividend yield
    0.58 %     0.69 %     0.57 %     1.05 %
Expected volatility
    45.95 %     47.84 %     46.18 %     48.52 %
Expected life in years
    6       6       6       6  

8


Table of Contents

2. Comprehensive Income

Comprehensive income for the three and nine months ended September 30, 2004 and 2003 is as follows:

                                 
    Three Months Ended   Nine Months Ended
    September 30,
  September 30,
    2004
  2003
  2004
  2003
Net income
  $ 21,620     $ 18,028     $ 41,168     $ 47,256  
Other comprehensive (loss) income, net of tax:
                               
Cumulative translation adjustment
    282       319       (1,721 )     2,692  
Change in unrealized loss on debt securities
    26       26       78       78  
Change in unrealized fair value of cash flow hedges
    32             (838 )      
 
   
 
     
 
     
 
     
 
 
Comprehensive income
  $ 21,960     $ 18,373     $ 38,687     $ 50,026  
 
   
 
     
 
     
 
     
 
 

Accumulated other comprehensive loss reported on our balance sheet at September 30, 2004 includes the following, net of tax: $11,640 of cumulative translation adjustment, $185 of unrealized loss on debt securities, ($479) of unrealized fair value of cash flow hedges and $765 of minimum pension liability adjustments.

3. Goodwill and Other Intangibles

Goodwill

General—At September 30, 2004 and December 31, 2003, our goodwill balances were $232,364 and $219,033, respectively, attributable to the excess of the purchase price over the fair value of net assets acquired relative to acquisitions within our North America and EAME segments.

The increase in goodwill primarily relates to direct acquisition costs and final asset and liability valuations associated with our 2003 acquisitions of Petrofac and John Brown, a contingent earnout obligation associated with our 2000 acquisition of Howe-Baker International L.L.C. (“Howe-Baker”), the impact of foreign currency translation and a reduction in accordance with SFAS No. 109, “Accounting for Income Taxes,” where tax goodwill exceeded book goodwill.

The change in goodwill by segment for the nine months ended September 30, 2004 is as follows:

                         
    North America
  EAME
  Total
Balance at December 31, 2003
  $ 199,210     $ 19,823     $ 219,033  
Adjustments associated with prior year acquisitions and contingent earnout obligations
    5,551       7,780       13,331  
 
   
 
     
 
     
 
 
Balance at September 30, 2004
  $ 204,761     $ 27,603     $ 232,364  
 
   
 
     
 
     
 
 

Impairment TestingSFAS No. 142 “Goodwill and Other Intangible Assets” prescribes a two-phase process for impairment testing of goodwill, which is performed annually, absent any indicators of impairment. The first phase screens for impairment, while the second phase (if necessary) measures the impairment. We have elected to perform our annual analysis during the fourth quarter of each year based upon goodwill balances as of the end of the third calendar quarter. Although no indicators of impairment have been identified during 2004, there can be no assurance that future goodwill impairment tests will not result in a charge to earnings.

9


Table of Contents

Other Intangible Assets

In accordance with SFAS No. 142, the following table provides information concerning our other intangible assets for the periods ended September 30, 2004 and December 31, 2003:

                                 
    September 30, 2004
  December 31, 2003
    Gross Carrying   Accumulated   Gross Carrying   Accumulated
    Amount
  Amortization
  Amount
  Amortization
Amortized intangible assets
                               
Technology (3 to 11 years)
  $ 6,221     $ (4,431 )   $ 6,221     $ (3,795 )
Non-compete agreements (4 to 8 years)
    4,810       (3,210 )     4,810       (2,648 )
Strategic alliances, customer contracts, patents (3 to 11 years)
    2,695       (1,282 )     2,695       (1,051 )
 
   
 
     
 
     
 
     
 
 
Total
  $ 13,726     $ (8,923 )   $ 13,726     $ (7,494 )
 
   
 
     
 
     
 
     
 
 
Unamortized intangible assets
                               
Tradenames
  $ 24,717             $ 24,717          
 
   
 
             
 
         

The changes in other intangibles relate to additional amortization expense.

4. Financial Instruments

Forward ContractsAt September 30, 2004 our forward contracts to hedge intercompany loans and certain operating exposures are summarized as follows:

                     
        Contract   Weighted Average
Currency Sold
  Currency Purchased
  Amount (1)
  Contract Rate
Forward contracts to hedge intercompany loans: (2)        
Euro
  U.S. Dollar   $ 9,576       0.83  
U.S. Dollar
  British Pound   $ 12,790       0.56  
U.S. Dollar
  Canadian Dollar   $ 12,422       1.30  
U.S. Dollar
  Australian Dollar   $ 4,385       1.44  
U.S. Dollar
  South African Rand   $ 582       6.44  
Forward contracts to hedge certain operating exposures: (3)
U.S. Dollar
  Euro   $ 13,465       0.84  
U.S. Dollar
  South African Rand   $ 7,491       6.67  
U.S. Dollar
  Qatari Rial   $ 1,884       3.63  
U.S. Dollar
  British Pound   $ 662       0.56  
U.S. Dollar
  Japanese Yen   $ 477       104.82  

(1)   Represents notional U.S. dollar equivalent at inception of contract.
 
(2)   Contracts generally mature within six days of quarter-end.
 
(3)   Contracts mature within nine months of quarter-end and were designated as “cash flow hedges” under SFAS No. 133, “Accounting for Derivative Instruments and Hedging Activities.” At September 30, 2004, the fair value of these contracts, recorded in other current assets on our consolidated balance sheets, was $736 (see Note 2). Any hedge ineffectiveness was not significant.

10


Table of Contents

5. Retirement Benefits

We previously disclosed in our financial statements for the year ended December 31, 2003, that in 2004 we expected to contribute $4,929 and $3,006 to our defined benefit and other postretirement plans, respectively. The following table provides contribution information for our defined benefit and postretirement plans as of September 30, 2004:

                 
    Defined   Other Postretirement
    Benefit Plans
  Benefits
Contributions made through September 30, 2004
  $ 3,524     $ 2,361  
Remaining contributions expected for 2004
    1,106       582  
 
   
 
     
 
 
Total contributions expected for 2004
  $ 4,630     $ 2,943  
 
   
 
     
 
 

The following table provides combined information for our defined benefit and other postretirement plans:

Components of Net Periodic Benefit Cost

                                 
    Defined   Other Postretirement
    Benefit Plans
  Benefits
Three months ended September 30,
  2004
  2003
  2004
  2003
Service cost
  $ 1,378     $ 821     $ 316     $ 419  
Interest cost
    1,202       294       490       474  
Expected return on plan assets
    (1,383 )     (366 )            
Amortization of prior service costs
    4       2       (67 )     (25 )
Recognized net actuarial loss
    72       102       65       24  
 
   
 
     
 
     
 
     
 
 
Net periodic benefit cost
  $ 1,273     $ 853     $ 804     $ 892  
 
   
 
     
 
     
 
     
 
 
                                 
Nine months ended September 30,
  2004
  2003
  2004
  2003
Service cost
  $ 4,218     $ 1,305     $ 948     $ 1,259  
Interest cost
    2,003       807       1,471       1,345  
Expected return on plan assets
    (2,408 )     (999 )            
Amortization of prior service costs
    12       7       (201 )     (76 )
Recognized net actuarial loss
    213       308       195       71  
 
   
 
     
 
     
 
     
 
 
Net periodic benefit cost
  $ 4,038     $ 1,428     $ 2,413     $ 2,599  
 
   
 
     
 
     
 
     
 
 

11


Table of Contents

6. Segment Information

We manage our operations by four geographic segments: North America; Europe, Africa, Middle East; Asia Pacific; and Central and South America. Each geographic segment offers similar services.

The Chief Executive Officer evaluates the performance of these four segments based on revenue and income from operations. Each segment’s performance reflects the allocation of corporate costs, which were based primarily on revenue. Intersegment revenue was not material.

                                 
    Three Months Ended   Nine Months Ended
    September 30,
  September 30,
    2004
  2003
  2004
  2003
Revenue
                               
North America
  $ 263,054     $ 256,222     $ 762,856     $ 699,418  
Europe, Africa, Middle East
    144,516       92,771       362,664       229,412  
Asia Pacific
    38,182       56,974       139,514       149,580  
Central and South America
    19,787       23,156       59,431       62,331  
 
   
 
     
 
     
 
     
 
 
Total revenue
  $ 465,539     $ 429,123     $ 1,324,465     $ 1,140,741  
 
   
 
     
 
     
 
     
 
 
Income From Operations
                               
North America
  $ 22,525     $ 21,255     $ 47,380     $ 50,905  
Europe, Africa, Middle East
    8,879       2,691       4,180       8,594  
Asia Pacific
    1,088       2,003       3,638       6,302  
Central and South America
    3,247       2,113       8,501       7,386  
 
   
 
     
 
     
 
     
 
 
Total income from operations
  $ 35,739     $ 28,062     $ 63,699     $ 73,187  
 
   
 
     
 
     
 
     
 
 

7. Commitments and Contingencies

Antitrust Proceedings—On October 25, 2001, the U.S. Federal Trade Commission (the “FTC” or the “Commission”) announced its decision to file an administrative complaint (the “Complaint”) challenging our February 2001 acquisition of certain assets of the Engineered Construction Division of PDM that we acquired together with certain assets of the Water Division of PDM (The Engineered Construction and Water Divisions of PDM are hereafter sometimes referred to as the “PDM Divisions”). The FTC’s Complaint alleged that the acquisition violated Section 7 of the Clayton Antitrust Act and Section 5 of the Federal Trade Commission Act by threatening to substantially lessen competition in four specific markets in which both we and PDM had competed in the United States: liquefied natural gas storage tanks and associated facilities constructed in the United States; liquefied nitrogen, liquefied oxygen and liquefied argon storage tanks constructed in the United States; liquefied petroleum gas storage tanks constructed in the United States; and field erected thermal vacuum chambers (used for the testing of satellites) constructed in the United States. The FTC’s Complaint asserted that the consequence of the acquisition will be increased prices in these four markets.

A trial before an FTC Administrative Law Judge was concluded on January 16, 2003. On June 12, 2003, the FTC Administrative Law Judge issued his ruling. The ruling found that our acquisition of PDM assets threatens to substantially lessen competition in the four markets identified above in which both CB&I and PDM participated. As a result of this finding by the FTC Administrative Law Judge, we have been ordered to divest within 180 days of a final order all physical assets, intellectual property and any uncompleted construction contracts of the PDM Divisions that we acquired from PDM to a purchaser approved by the FTC that is able to utilize those assets as a viable competitor.

We believe the FTC Administrative Law Judge’s ruling is inconsistent with the law and facts presented at trial. We have appealed the ruling to the full Federal Trade Commission. In addition, the FTC Staff has appealed the sufficiency of the remedies contained in the ruling to the full Federal Trade Commission. Pending issuance of a

12


Table of Contents

final order by the Commission, we are subject to an interim order designed to preserve the status quo of the PDM assets, including a requirement that we notify the FTC 60 days before taking any action to dispose of any PDM assets at our Provo, Utah fabrication facility. On November 12, 2003, oral arguments were held before the Commission, which will issue its decision in due course. Until the FTC order becomes final, we expect the impact on our earnings will be minimal. However, the remedies contained in the order, if implemented, could have an adverse effect on us, including an expense relating to a potential write-down of the net book value of the divested assets. If additional remedies sought by the FTC staff are also implemented by the Full Commission, there may be additional adverse financial effects on us.

In addition, we were served with a subpoena for documents on July 23, 2003, by the Philadelphia office of the U.S. Department of Justice, Antitrust Division. The subpoena seeks documents that are in part related to matters that were the subject of testimony in the FTC administrative law trial, as well as documents relating to our Water Division. We are cooperating fully with the investigation. We cannot assure you that proceedings will not result from this investigation.

Environmental Matters—Our operations are subject to extensive and changing U.S. federal, state and local laws and regulations and laws outside the U.S. establishing health and environmental quality standards, including those governing discharges and pollutants into the air and water and the management and disposal of hazardous substances and wastes. This exposes us to potential liability for personal injury or property damage caused by any release, spill, exposure or other accident involving such substances or wastes.

In connection with the historical operation of our facilities, substances which currently are or might be considered hazardous were used or disposed of at some sites that will or may require us to make expenditures for remediation. In addition, we have agreed to indemnify parties to whom we have sold facilities for certain environmental liabilities arising from acts occurring before the dates those facilities were transferred. We are not aware of any manifestation by a potential claimant of its awareness of a possible claim or assessment with respect to any such facility.

We believe that we are currently in compliance, in all material respects, with all environmental laws and regulations. We do not anticipate that we will incur material capital expenditures for environmental controls or for investigation or remediation of environmental conditions during the remainder of 2004 or 2005.

Other—We are a defendant in a number of lawsuits arising in the normal course of business, including among others, lawsuits wherein plaintiffs allege exposure to asbestos due to work we may have performed at various locations. We have never been a manufacturer, distributor or supplier of asbestos products, and we have in place appropriate insurance coverage for the type of work that we have performed. During 2004, we were named as a defendant in additional asbestos-related lawsuits. To date, the claims which have been resolved have been dismissed or settled without a material impact on our operating results or financial position and we do not currently believe that unresolved asserted claims will have a material adverse effect on our future results of operations or financial position. As a matter of standard policy, we continually review our litigation accrual and as further information is known on pending cases, increases or decreases, as appropriate, may be recorded in accordance with SFAS No. 5, “Accounting for Contingencies.”

13


Table of Contents

Item 2 — Management’s Discussion and Analysis of Financial Condition
and Results of Operations

The following “Management’s Discussion and Analysis of Financial Condition and Results of Operations” is provided to assist readers in understanding our financial performance during the periods presented and significant trends which may impact our future performance. This discussion should be read in conjunction with our Consolidated Financial Statements and the related notes thereto included elsewhere in this quarterly report.

We are a global specialty engineering, procurement and construction company serving customers in several primary end markets, including hydrocarbon refining, natural gas, water and the energy sector in general. We have been helping our customers store and process the earth’s natural resources for more than 100 years by supplying a comprehensive range of engineered steel structures and systems. We offer a complete package of design, engineering, fabrication, procurement, construction and maintenance services. Our projects include hydrocarbon processing plants, liquefied natural gas (“LNG”) terminals and peak shaving plants, offshore structures, pipelines, bulk liquid terminals, water storage and treatment facilities, and other steel structures and their associated systems. We have been continuously engaged in the engineering and construction industry since our founding in 1889.

Results of Operations

New Business Taken/Backlog—During the three months ended September 30, 2004, new business taken, representing the value of new project commitments received during a given period, was $503.7 million, compared with $444.7 million in the third quarter of 2003. These commitments are included in backlog until work is performed and revenue is recognized or until cancellation. Significant new business during the quarter included an LNG peak shaving project and refinery clean fuels projects in North America. New business taken for the first nine months of 2004 was $1.25 billion, compared with $1.31 billion for the same period last year.

Backlog at September 30, 2004 stood at $1.51 billion compared with $1.65 billion at September 30, 2003.

Revenue—Revenue during the three months ended September 30, 2004 increased 8% to $465.5 million from $429.1 million in the third quarter of 2003. Our revenue fluctuates based on the changing project mix and is dependent on the amount and timing of new awards and on other matters such as project schedules. During the quarter, revenue increased 3% in the North America segment and 56% in the Europe, Africa, Middle East (“EAME”) segment. Revenue declined 33% in the Asia Pacific (“AP”) segment, primarily in Australia, and 15% in the Central and South America (“CSA”) segment. Revenue for the first nine months of 2004 increased 16% to $1.32 billion, compared with $1.14 billion in the year-earlier period.

Gross Profit—Gross profit for the quarter increased 16% to $59.7 million, or 12.8% of revenue, compared with 12.0% of revenue for the comparable period in 2003. The increase was primarily attributable to the timing and mix of projects being executed. For the first nine months of 2004, gross profit was $136.0 million compared with $140.5 million in the comparable 2003 period. Year-to-date gross profit decreased primarily due to the recognition of potentially unrecoverable costs on two projects, one in our EAME segment’s Saudi Arabia region that is substantially complete and the other in our North America segment that has been completed.

Saudi Arabian Project

The Saudi project was forecasted to close in a loss position of $1.4 million as of the end of 2003. In the first quarter of 2004 we recognized unanticipated costs for work performed on the project for which we were contractually obligated without the benefit of immediate owner approval. The increased costs were provided for in the period, resulting in a total charge of $6.9 million in the first quarter.

Events in the Saudi Arabia region of our EAME segment during the second quarter resulted in an unanticipated level of uncertainty and instability in the region. As a result of disruptions, real or perceived, caused by terrorist activity beginning in May 2004, we incurred additional costs and encountered unexpected difficulties and delays on the Saudi project due to increased physical security requirements and the inefficiencies, delays and disruption

14


Table of Contents

caused by the need to replace employees choosing to depart the Kingdom. In the second quarter we increased our estimate of all costs expected to be incurred to complete the project. As the project was still forecasted to result in a loss in the second quarter, additional provision for such loss was made, resulting in a $16.4 million charge in the second quarter.

As of September 30, 2004, we have recognized $0.5 million of revenue for unapproved change orders for the project. Provision for additional loss on the project resulted in a $2.1 million charge to earnings in the third quarter.

Other than the Saudi project, we have active smaller projects in the Saudi Arabia region of our EAME segment where terrorist activity might significantly increase our costs or cause a delay in the completion of a project. We have taken steps to reduce risks from terrorist activity, including moving certain employees and support services out of Saudi Arabia and continuing to implement appropriate security measures at our jobsites and facilities. While no assurances can be given, we do not believe that we have any material risks at the present time attributable to terrorist activity in Saudi Arabia.

North American Project

On the North America segment project, a major general contractor for us (Jones LG LLC) filed for bankruptcy in late September 2003, and we undertook to take over and complete the project on an expedited basis to ensure that our significant client’s requirements were met. During the fourth quarter of 2003, work that had been performed by the contractor’s subcontractors was suspended at a critical stage pending authorization from the bankruptcy court to proceed. Also during the fourth quarter of 2003, the general contractor gave us an estimate of the amount of the work completed and remaining to be completed. Late in the fourth quarter, we began to mobilize and believed we could perform within the budget. During the first quarter of 2004, costs increased from the impact of our taking over the work and included the continuation of mobilization; hiring and deployment of craft labor; selection of subcontractors and planning and organization of the takeover of the work and performance of work that had not been satisfactorily completed by the general contractor or its subcontractors. An $8.0 million charge to earnings was recognized in the first quarter for the increase in forecasted total costs and the resulting reduced forecasted gross margin on the project.

During the second quarter of 2004, our forecast of total project costs increased as a result of a series of unexpected events that required us to perform unplanned work and incur unforecasted costs including the rework of components of the most critical equipment on the project, decreases in labor productivity and longer than anticipated equipment utilization. Additionally, commissioning and preparation for startup of the facility began before construction was complete and much of the work had to be completed on an expedited basis in order to support an aggressive commissioning and start up program, necessitating additional costs. Due to these previously unforeseen costs, the project was now forecasted to result in a negative gross margin. As a result, a provision for such loss was made, resulting in a $15.0 million charge to earnings in the second quarter.

Selling and Administrative Expenses—Selling and administrative expense for the three months ended September 30, 2004 was $23.3 million, or 5.0% of revenue, compared with $25.1 million, or 5.8% of revenue, for the comparable period in 2003. The absolute dollar decrease compared with 2003 primarily relates to lower incentive program costs.

Income from Operations—Income from operations in the third quarter of 2004 increased 27% to $35.7 million, compared with $28.1 million in the comparable 2003 period, primarily due to the combination of higher revenue in the EAME segment and continued control of overhead and administrative expenses. For the first nine months of 2004, income from operations was $63.7 million, compared with $73.2 million in the first nine months of 2003.

Income Tax Expense—Income tax expense for the three months ended September 30, 2004 and 2003 was $11.4 million, or 33.7% of pre-tax income and $8.1 million, or 30.4% of pre-tax income, respectively. The rate increase compared to 2003 is due to a larger portion of our taxable income being attributable to North America and the United Kingdom.

15


Table of Contents

Liquidity and Capital Resources

At September 30, 2004, cash and cash equivalents totaled $143.3 million.

Operating—During the first nine months of 2004, our operations generated $37.9 million of cash flows.

Investing—In the first nine months of 2004, we incurred $12.0 million for capital expenditures. For 2004, capital expenditures are anticipated to be in the $15.0 to $20.0 million range. Our utilization of cash also included $10.5 million of deferred purchase consideration, including $8.6 million of contingent consideration associated with our acquisition of Howe-Baker International, L.L.C. (“Howe-Baker”) in 2000.

In connection with our acquisition of Howe-Baker we assumed two earnout arrangements contingent upon the performance of the underlying acquired entities. One of the arrangements, which has and will continue to require us to make cash payments to the previous owners, expired in July 2004 (of which $1.4 million is included in accrued liabilities with final settlement expected in the first quarter of 2005), while the other arrangement was settled during 2003.

We continue to evaluate and selectively pursue opportunities for expansion of our business through acquisition of complementary businesses. These acquisitions, if they arise, may involve the use of cash or may require debt or equity financing.

Financing—Net cash flows provided by financing activities were $13.8 million, primarily attributable to the issuance of common stock resulting from the exercise of stock options and short-term international borrowings. Cash dividends of $5.7 million were paid during the first nine months of 2004.

Our primary source of liquidity is cash flow generated from operations. Capacity under revolving credit agreements is also available, if necessary, to fund operating or investing activities. We have a three-year $233.3 million revolving credit facility and a five-year $116.7 million letter of credit facility, which terminate in August 2006 and August 2008, respectively. Both facilities are committed and unsecured. As of September 30, 2004, no direct borrowings existed under the revolving credit facility, but we had issued $83.5 million of letters of credit under the three-year facility and $51.0 million under the five-year facility. As of September 30, 2004, we had $215.5 million of available capacity under these facilities. The facilities contain certain restrictive covenants including minimum levels of net worth, fixed charge and leverage ratios. The facilities also place other restrictions on us including subsidiary indebtedness, sales of assets, liens, investments, type of business conducted, and mergers and acquisitions. We were in compliance with all covenants at September 30, 2004.

We also have various short-term, uncommitted revolving credit facilities across several geographic regions of approximately $284.2 million. These facilities are generally used to provide letters of credit or bank guarantees to customers in the ordinary course of business to support advance payments, as performance guarantees or in lieu of retention on our contracts. At September 30, 2004, we had available capacity of $123.6 million under these uncommitted facilities. In addition to providing letters of credit or bank guarantees, we also provide surety bonds in the ordinary course of business to support our contract performance.

16


Table of Contents

As of September 30, 2004, the following commitments were in place to support our ordinary course obligations:

                                                                                      
            Amounts of Commitments by Expiration Period
   
(In thousands)
  Total
  Less than 1 Year
  1-3 Years
  4-5 Years
  After 5 Years
Letters of Credit/Bank Guarantees
  $ 295,063     $ 188,609     $ 92,400     $ 14,054     $  
Surety Bonds
    427,338       342,921       84,142       275        
 
   
     
     
     
     
 
Total Commitments
  $ 722,401     $ 531,530     $ 176,542     $ 14,329     $  
 
   
 
     
 
     
 
     
 
     
 
 

Note: Includes $22,235 of letters of credit issued in support of our insurance program.

We believe funds generated by operations, amounts available under existing credit facilities and external sources of liquidity, such as the issuance of debt and equity instruments, will be sufficient to finance capital expenditures, the settlement of earnout obligations, the settlement of commitments and contingencies (as fully described in Note 7 to our Consolidated Financial Statements) and working capital needs for the foreseeable future. However, there can be no assurance that such funding will be available, as our ability to generate cash flows from operations and our ability to access funding under the revolving credit facilities may be impacted by a variety of business, economic, legislative, financial and other factors which may be outside of our control. Additionally, while we currently have significant, uncommitted bonding facilities, primarily to support various commercial provisions in our engineering and construction contracts, a termination or reduction of these bonding facilities could result in the utilization of letters of credit in lieu of performance bonds, thereby reducing our available capacity under the revolving credit facilities. There can be no assurance that such facilities will be available at reasonable terms to service our ordinary course obligations.

Off-Balance Sheet Arrangements

We use operating leases for facilities and equipment when they make economic sense. In 2001, we entered into a sale (for approximately $14.0 million) and leaseback transaction of our Plainfield, Illinois administrative office with a lease term of 20 years. The leaseback structure’s future payments are accounted for as an operating lease. Rentals under this and all other lease commitments are reflected in rental expense.

We have no other off-balance sheet arrangements.

New Accounting Standards

In December 2003, the Financial Accounting Standards Board (“FASB”) issued Statement of Financial Accounting Standards (“SFAS”) No. 132 (revised 2003), “Employers’ Disclosures about Pensions and Other Postretirement Benefits.” The revised standard requires annual and interim disclosures in addition to those in the original standard concerning the assets, obligations, cash flows, and net periodic benefit cost of defined benefit pension plans and other defined benefit postretirement plans. This statement is effective for fiscal years ending after December 15, 2003. See Note 5 for the interim disclosure requirements of SFAS No. 132 (revised 2003).

In May 2004, the FASB issued FASB Staff Position (“FSP”) No. 106-2 (“FSP 106-2”), “Accounting and Disclosure Requirements Related to the Medicare Prescription Drug, Improvement and Modernization Act of 2003,” which supersedes FSP 106-1. FSP 106-2 provides guidance on the accounting for the effects of the Medicare Prescription Drug, Improvement and Modernization Act of 2003 (the “Act”) for employers that sponsor postretirement health care plans that provide prescription drug benefits. FSP 106-2 also requires certain disclosures regarding the effect of the federal subsidy provided by the Act. FSP 106-2 is effective for the first interim and annual period beginning after June 15, 2004. Although we are currently evaluating our qualification status for any Medicare Prescription Drug subsidies, the effect of our adoption of FSP 106-2 is not anticipated to have a significant impact on our financial condition or results of operations.

17


Table of Contents

Critical Accounting Policies

In general, there have been no significant changes in our critical accounting policies since December 31, 2003. For a detailed discussion of these policies, please see Item 7 of our annual report on Form 10-K for the year ended December 31, 2003. The following provides further clarification to our revenue recognition policy:

Revenue Recognition—Revenue is recognized using the percentage-of-completion method. A significant portion of our work is performed on a fixed price or lump sum basis. The balance of our work is performed on variations of cost reimbursable and target price approaches. Contract revenue is accrued based on the percentage that actual costs-to-date bear to total estimated costs. We utilize this cost-to-cost approach as we believe this method is less subjective than relying on assessments of physical progress. We follow the guidance of the Statement of Position 81-1, “Accounting for Performance of Construction-Type and Certain Production-Type Contracts,” for accounting policy relating to our use of the percentage-of-completion method, estimating costs, revenue recognition and claim recognition. The use of estimated cost to complete each contract, while the most widely recognized method used for percentage-of-completion accounting, is a significant variable in the process of determining income earned and is a significant factor in the accounting for contracts. The cumulative impact of revisions in total cost estimates during the progress of work is reflected in the period in which these changes become known. Due to the various estimates inherent in our contract accounting, actual results could differ from those estimates.

Contract revenue reflects the original contract price adjusted for approved change orders and estimated minimum recoveries of unapproved change orders and claims. We recognize unapproved change orders and claims to the extent that related costs have been incurred when it is probable that they will result in additional contract revenue and their value can be reliably estimated. At September 30, 2004 and December 31, 2003, we had net outstanding unapproved change orders/claims recognized of $23.4 million and $7.0 million, respectively. Losses expected to be incurred on contracts in progress are charged to income in the period such losses are known. Provisions for additional costs associated with contracts projected to be in a significant loss position at September 30, 2004 resulted in a $2.1 million and $48.4 million charge to income in the three and nine month periods ended September 30, 2004, respectively.

Forward-Looking Statements

This quarterly report on Form 10-Q contains forward-looking statements. You should read carefully any statements containing the words “expect,” “believe,” “anticipate,” “project,” “estimate,” “predict,” “intend,” “should,” “could,” “may,” “might,” or similar expressions or the negative of any of these terms.

Forward-looking statements involve known and unknown risks and uncertainties. In addition to the material risks listed under “Risk Factors,” as set forth in our Form 10-K dated March 12, 2004, that may cause our actual results, performance or achievements to be materially different from those expressed or implied by any forward-looking statements, the following factors could also cause our results to differ from such statements:

  our ability to realize cost savings from our expected execution performance of contracts;
 
  the uncertain timing and the funding of new contract awards, and project cancellations and operating risks;
 
  cost overruns on fixed price contracts;
 
  risks associated with percentage of completion accounting;
 
  changes in the costs or availability of or delivery schedule for components and materials;
 
  increased competition;
 
  fluctuating revenues resulting from a number of factors, including the cyclic nature of the individual markets in which our customers operate;

18


Table of Contents

  lower than expected activity in the hydrocarbon industry, demand from which is the largest component of our revenue;
 
  the expected growth in our primary end markets does not occur;
 
  risks inherent in our acquisition strategy and our ability to obtain financing for proposed acquisitions;
 
  our ability to integrate and successfully operate acquired businesses and the risks associated with those businesses;
 
  adverse outcomes of pending claims or litigation or the possibility of new claims or litigation;
 
  the ultimate outcome or effect of the pending FTC proceeding and DOJ investigation on our business, financial condition and results of operations.
 
  lack of necessary liquidity to finance expenditures prior to the receipt of payment for the performance of contracts and to provide bid and performance bonds and letters of credit securing our obligations under our bids and contracts;
 
  proposed and actual revisions to U.S. tax laws that seek to increase income taxes payable by certain international companies;
 
  political and economic conditions including, but not limited to, war, conflict or civil or economic unrest in countries in which we operate; and
 
  a downturn in the economy in general.

Although we believe the expectations reflected in our forward-looking statements are reasonable, we cannot guarantee future performance or results. We are not obligated to update or revise any forward-looking statements, whether as a result of new information, future events or otherwise. You should consider these risks when reading any forward-looking statements.

Item 3. Quantitative and Qualitative Disclosures About Market Risk

We are exposed to market risk from changes in foreign currency exchange rates, which may adversely affect our results of operations and financial condition. One exposure to fluctuating exchange rates relates to the effects of translating the financial statements of our non-U.S. subsidiaries, which are denominated in currencies other than the U.S. dollar, into the U.S. dollar. The foreign currency translation adjustments are recognized in shareholders’ equity in accumulated other comprehensive income (loss) as cumulative translation adjustment, net of tax. We generally do not hedge our exposure to potential foreign currency translation adjustments.

Another form of foreign currency exposure relates to our non-U.S. subsidiaries’ normal contracting activities. We generally try to limit our exposure to foreign currency fluctuations in most of our engineering and construction contracts through provisions that require client payments in U.S. dollars or other currencies corresponding to the currency in which costs are incurred. As a result, we generally do not need to hedge foreign currency cash flows for contract work performed. However, where construction contracts do not contain foreign currency provisions, we use forward exchange contracts to hedge foreign currency transaction exposure. The gains and losses on these contracts offset changes in the value of the related exposures. As of September 30, 2004, the notional amount of cash flow hedge contracts outstanding was $24.0 million, and the fair value of these contracts was an asset of approximately $0.7 million. The terms of these contracts generally do not exceed one year.

In circumstances where intercompany loans and/or borrowings are in place with non-U.S. subsidiaries, we will also use forward contracts. If the timing or amount of foreign-denominated cash flows varies, we incur foreign exchange

19


Table of Contents

gains or losses, which are included in the consolidated statements of income. We do not use financial instruments for trading or speculative purposes.

We maintain operations and have construction projects in Venezuela, which continued to experience negative political and economic conditions during the first nine months of 2004. As a result, the Venezuelan Bolivar, which devalued more than 85% against the U.S. dollar in 2002, was subject to trading restrictions in 2003 and the first nine months of 2004. As of September 30, 2004, we had $0.8 million of net assets in Venezuela that are subject to foreign currency translation adjustments. As noted above, the exposure on our construction projects is generally limited by contractual provisions. However, we will continue to face currency exposure on our net assets.

The carrying value of our cash and cash equivalents, accounts receivable, accounts payable, notes payable and forward contracts approximates their fair values because of the short-term nature of these instruments. See Note 4 to our Consolidated Financial Statements for quantification of our financial instruments.

Item 4. Controls and Procedures

Disclosure Controls and Procedures—As of the end of the period covered by this quarterly report on Form 10-Q, we carried out an evaluation, under the supervision and with the participation of our management, including the Chief Executive Officer (CEO) and Chief Financial Officer (CFO), of the effectiveness of the design and operation of our disclosure controls and procedures (as such term is defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934, as amended (the “Exchange Act”)). Based upon such evaluation, the CEO and CFO have concluded that, as of the end of such period, our disclosure controls and procedures are effective to ensure information required to be disclosed in reports that we file or submit under the Exchange Act is recorded, processed, summarized and reported within the time period specified in the Securities and Exchange Commission’s rules and forms.

Changes in Internal Controls—There was no significant change in our internal controls over financial reporting that occurred during our most recently completed fiscal quarter, that has materially affected, or is reasonably likely to materially affect, our internal control over financial reporting.

PART II.      OTHER INFORMATION

Item 1. Legal Proceedings

Antitrust Proceedings—On October 25, 2001, the U.S. Federal Trade Commission (the “FTC” or the “Commission”) announced its decision to file an administrative complaint (the “Complaint”) challenging our February 2001 acquisition of certain assets of the Engineered Construction Division of PDM that we acquired together with certain assets of the Water Division of PDM (The Engineered Construction and Water Divisions of PDM are hereafter sometimes referred to as the “PDM Divisions”). The FTC’s Complaint alleged that the acquisition violated Section 7 of the Clayton Antitrust Act and Section 5 of the Federal Trade Commission Act by threatening to substantially lessen competition in four specific markets in which both we and PDM had competed in the United States: liquefied natural gas storage tanks and associated facilities constructed in the United States; liquefied nitrogen, liquefied oxygen and liquefied argon storage tanks constructed in the United States; liquefied petroleum gas storage tanks constructed in the United States; and field erected thermal vacuum chambers (used for the testing of satellites) constructed in the United States. The FTC’s Complaint asserted that the consequence of the acquisition will be increased prices in these four markets.

A trial before an FTC Administrative Law Judge was concluded on January 16, 2003. On June 12, 2003, the FTC Administrative Law Judge issued his ruling. The ruling found that our acquisition of PDM assets threatens to substantially lessen competition in the four markets identified above in which both CB&I and PDM participated. As a result of this finding by the FTC Administrative Law Judge, we have been ordered to divest within 180 days of a final order all physical assets, intellectual property and any uncompleted construction contracts of the PDM Divisions that we acquired from PDM to a purchaser approved by the FTC that is able to utilize those assets as a viable competitor.

20


Table of Contents

We believe the FTC Administrative Law Judge’s ruling is inconsistent with the law and facts presented at trial. We have appealed the ruling to the full Federal Trade Commission. In addition, the FTC Staff has appealed the sufficiency of the remedies contained in the ruling to the full Federal Trade Commission. Pending issuance of a final order by the Commission, we are subject to an interim order designed to preserve the status quo of the PDM assets, including a requirement that we notify the FTC 60 days before taking any action to dispose of any PDM assets at our Provo, Utah fabrication facility. On November 12, 2003, oral arguments were held before the Commission, which will issue its decision in due course. Until the FTC order becomes final, we expect the impact on our earnings will be minimal. However, the remedies contained in the order, if implemented, could have an adverse effect on us, including an expense relating to a potential write-down of the net book value of the divested assets. If additional remedies sought by the FTC staff are also implemented by the Full Commission, there may be additional adverse financial effects on us.

In addition, we were served with a subpoena for documents on July 23, 2003, by the Philadelphia office of the U.S. Department of Justice, Antitrust Division. The subpoena seeks documents that are in part related to matters that were the subject of testimony in the FTC administrative law trial, as well as documents relating to our Water Division. We are cooperating fully with the investigation. We cannot assure you that proceedings will not result from this investigation.

Environmental Matters—Our operations are subject to extensive and changing U.S. federal, state and local laws and regulations and laws outside the U.S. establishing health and environmental quality standards, including those governing discharges and pollutants into the air and water and the management and disposal of hazardous substances and wastes. This exposes us to potential liability for personal injury or property damage caused by any release, spill, exposure or other accident involving such substances or wastes.

In connection with the historical operation of our facilities, substances which currently are or might be considered hazardous were used or disposed of at some sites that will or may require us to make expenditures for remediation. In addition, we have agreed to indemnify parties to whom we have sold facilities for certain environmental liabilities arising from acts occurring before the dates those facilities were transferred. We are not aware of any manifestation by a potential claimant of its awareness of a possible claim or assessment with respect to any such facility.

We believe that we are currently in compliance, in all material respects, with all environmental laws and regulations. We do not anticipate that we will incur material capital expenditures for environmental controls or for investigation or remediation of environmental conditions during the remainder of 2004 or 2005.

Other—We are a defendant in a number of lawsuits arising in the normal course of business, including among others, lawsuits wherein plaintiffs allege exposure to asbestos due to work we may have performed at various locations. We have never been a manufacturer, distributor or supplier of asbestos products, and we have in place appropriate insurance coverage for the type of work that we have performed. During 2004, we were named as a defendant in additional asbestos-related lawsuits. To date, the claims which have been resolved have been dismissed or settled without a material impact on our operating results or financial position and we do not currently believe that unresolved asserted claims will have a material adverse effect on our future results of operations or financial position. As a matter of standard policy, we continually review our litigation accrual and as further information is known on pending cases, increases or decreases, as appropriate, may be recorded in accordance with SFAS No. 5, “Accounting for Contingencies.”

21


Table of Contents

Item 6. Exhibits and Reports on Form 8-K

  (a)   Exhibits

  31.1   Certification Pursuant to Rule 13A-14 of the Securities Exchange Act of 1934 as Adopted Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
  31.2   Certification Pursuant to Rule 13A-14 of the Securities Exchange Act of 1934 as Adopted Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
  32.1   Certification pursuant to 18 U.S.C. Section 1350, as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.
 
  32.2   Certification pursuant to 18 U.S.C. Section 1350, as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.

  (b)   Reports on Form 8-K

      We filed a current report on Form 8-K on July 29, 2004. Under Item 12 (Results of Operations and Financial Condition) we furnished a copy of our press release dated July 29, 2004 announcing financial results for the quarter ended June 30, 2004.

22


Table of Contents

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned thereunto duly authorized.
         
  Chicago Bridge & Iron Company N.V.
 
 
  By:   Chicago Bridge & Iron Company B.V.    
  Its: Managing Director   
       
 
     
  /s/ RICHARD E. GOODRICH    
  Richard E. Goodrich   
Date: November 8, 2004  Managing Director (Principal Financial Officer)    
 

23


Table of Contents

EXHIBIT INDEX

 

  31.1   Certification Pursuant to Rule 13A-14 of the Securities Exchange Act of 1934 as Adopted Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
  31.2   Certification Pursuant to Rule 13A-14 of the Securities Exchange Act of 1934 as Adopted Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
  32.1   Certification pursuant to 18 U.S.C. Section 1350, as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.
 
  32.2   Certification pursuant to 18 U.S.C. Section 1350, as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.